Kitchen Gallery Design Consultancy & Association With Gallery Kitchen Design, Interiors & Furniture & G2Techk Solar Heating & Energy.

Kitchen Gallery Design Consultancy,  Gallery Kitchen Design, Interiors & Furniture and G2Techk Solar Heating & Energy Booking Terms & Conditions.

 

1. The role of The Kitchen Gallery Design Consultancy is to assist the client with the first part of the project and or with consultation and design services and all administration services related to the project and this is with the provision of a separate contract and separate payment terms agreed between the client and The Kitchen Gallery Design Consultancy. The remaining part of a project is generally reserved for the Gallery Kitchen Design, Interiors & Furniture operation and for whom contract and payment terms are entered into with the client at a later stage on a separate contract. The same applies where there are any later works as referred from or to G2Techk Solar Heating & Energy.

 

2. The work in the first stage part of the project with The Kitchen Gallery Design Consultancy involves initial showroom first contact consultation, collating a wide range of information needed from the Client, inspection, survey, photographic, measurement, planning considerations, architectural, structural and safety considerations and checks in regard to the kitchen, home, building premises, land or site and and any further consultations where required. The remaining element of the project is generally completed by our sister operation Gallery Kitchen Design, Interiors & Furniture and or G2Techk for build, exterior and renewable energy projects.

 

3. Any customer booking the services of The Kitchen Gallery Design Consultancy, or by way of its sister operations of Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy either at our showroom, in the home, at premises, on site, over the phone or by way of email, post, social media or other form of communication, do so on the basis that the customer is immediately regarded as the ‘Client’ and hence in the rest of these terms and conditions the customer is referred to as ‘The Client and by booking the services of The Kitchen Gallery Design Consultancy, or by way of its sister operations of Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy and do so, in acceptance of these terms and conditions, those of the general terms and conditions page of this website and those on any contractual agreement and or installation documentation.

 

4. The Kitchen Gallery Design Consultancy service is available for projects where urgent structural and or maintenance is required and or where there are safety concerns regarding electrical gas & or utility services and or where separate contract design and consultancy services are required and or needed in advance of the main installation project. The Kitchen Gallery Design Consultancy’s services will be required if the installed services (electrical , gas and or other utility services ) within the client’s / customers property, building, or room and or the building itself is more than ten years old, then this will require a separate technical site survey and meaning that further and on going consultations will be required with the Client. This is for the purposes of client insurance and safety risk. Consequently, The Client agrees to ensure that it does not hinder, prevent or obstruct either Gallery Kitchen Design , Interiors & Furniture and or G2Techk Solar Heating & Energy from referring The Client to the services of The Kitchen Gallery Design Consultancy.

 

5. At all times, the Client will be required to adhere to the requirements of clause 4 by allowing The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy to perform its duties regarding Clause 4, this clause and any other clauses in these terms and conditions and those in any written contract or installation document. The Client accepts in booking the services of The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy that in any circumstances whatsoever, where a client has failed to allow The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy to perform and or complete its duties related to clause 4 then the Client will be liable for all costs accrued by The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy in pursuit of dealing with and administrating on in relation to this clause.

 

6. The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and G2Techk Solar Heating & Energy will always take the time to try to fully understand the Clients requirements as well as project budget. At all times the Client must clarify their particular budget for the project/s to enable The Kitchen Gallery Design Consultancy,  Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy to complete its performance and duties in regard to design, work tasks and consultations to and for the Client. Any delay caused by the Client in either not providing and or failure to finalise this information with The Kitchen Gallery Design Consultancy, and or by way of Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy means that The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy are not liable for that delay, and the Client accepts that in such circumstances the Client forfeits all rights to automatic refunds of fees, and or deposits as the Client will remain liable for any administration costs, charges, fees and working time costs, consultation and legal costs caused as consequence of that delay.  

 

7. The changing economy, Brexit and the effects of the covid-19 pandemic have affected fabrication, manufacturing, and supply and demand. This has meant that businesses must cover themselves for risk. Businesses also seek to protect themselves from the possibility of clients’ and customers reneging on payments in the event where they become insolvent and or unable to pay for the services that The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy has been booked for, is administering on the Client’s behalf and or has completed. With these considerations in mind and based on past to experience since the business’ inception in 2003 we realised, and were professionally advised to the fact that the risk should be reduced and that our valuable time, bespoke consultation services and solutions should not be offered free of charge. The Kitchen Gallery Design Consultancy, is as the name, title and service implies, a consultancy business. This means that all general consultation, design consultation, design work, survey’s and any administration and services including any legal or general task costs whatsoever relating to the project are chargeable fee based services. This also applies to the services of Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.  

 

8. In consideration of the above clauses, when booking the services of The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy, the client does so on the basis that the client accepts that all general consultation, administration, marketing, design consultation, designing and or survey fees including time spent during the first meeting with the client, at the home, premises, land, building and or on site or at the premises of The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy  is a chargeable service at a fee rate of £250.00 per hour and recoverable from the Client at all times. 

 

9. The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy will only consult with the client at the first attendance at its premises and or at the client’s home, premises, building land or site on the basis that this is deemed as booking of The Kitchen Gallery Design Consultancy,  and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy (where the latter business’s services are required) and which are all chargeable services and fees and are to be written into the contract of The Kitchen Gallery Design Consultancy, and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy at the reported fee rate of  £250.00 per hour.

 

10. The Client accepts that at all times fees, charges, administration, consultation, design services, survey and or legal costs  and or time costs for any time spent whatsoever on the project can be recovered by The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy from the any deposit, fee and or charges paid by the Client and or that are written on any contract agreement or installation document. The Client remains liable for any additional fees, charges and costs above any deposit, fee or charges that the Client has paid to The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy for any administration, consultation, design services, survey, legal costs and for any time spent whatsoever on the project and or dealing with the requirements and any conduct or actions of the Client on the project.

 

11. As referred to earlier in these terms and conditions, The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy will only take a booking for its services and or visit a client’s premises, home, building, premises and or site on the basis that from the moment of booking that service or visit, the booker of the service or visit is regarded as the ‘Client’ and that the terms and conditions of the time spent with The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy during the first service meeting at showroom office or at any visit to the Client’s home business, land or site and even if booked by verbal means ( referred to as a verbal contract), or booked by way of telephone, email, letter or via social media or written into an agreement or contract is booked on the basis that it is regarded as a legally binding contract and a chargeable service.

 

12. The Client accepts that any time spent at the initial visit and or walk in at the premises of The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy  is time spent by The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy is a chargeable cost at the rate of £250 per hour and that will be factored into the first part of the project service contract fee.  

 

13. At all times, the Client accepts that all sketches, designs, CAD’s services and solutions remain the sole property of The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy until the client has satisfied the business terms, requirements and payment terms of The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy. The Client accepts that The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserves the right to determine the nature of the works, meaning of the works and level of any services, works, solutions and of any contract entered into with the Client. Unless specifically referred to in any contract between the Client and The Kitchen Gallery Design Consultancy, booked services do not automatically include design services. One such example would be where the Client requires consulting and pricing services only.

 

14. The Client accepts that design presentation is a condition of the Client providing the full information required by either or The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy to enable The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy to complete its design, administrative, safety, service and consultation tasks.

 

15. The Client accepts that at all times, The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy has no liability for service or refunds whatsoever in situations where the Client has failed to provide any part of or the full information to enable The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy to complete those design, consultation, administrative, service and consultation tasks and or where the Client has prevented and or caused delay in enabling The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy to complete design consultation, administration, service, general consultation, safety and or installation tasks and or where the Client’s conduct has led to The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy having to carry out additional time spent on the project in administrative tasks, and or to seek and gain legal services, advice and assistance. 

 

16. The Kitchen Gallery Design Consultancy, Gallery kitchen Design , Interiors & Furniture & G2Techk Solar Heating & Energy reserves the right to withhold all its services, solutions and products and or designs and consultations where the conduct of the Client has affected the business of The Kitchen Gallery Design Consultancy and or Gallery kitchen Design , Interiors & Furniture and or G2Techk Solar Heating & Energy and or caused loss of business to The Kitchen Gallery Design Consultancy, and or to Gallery kitchen Design, Interiors & Furniture and or to G2Techk Solar Heating & Energy until such a time that the Client has rectified the matter in regard to the cause of the Client conduct, and compensated The Kitchen Gallery Design Consultancy, and or Gallery kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy ‘s where any loss of business has occurred as a consequence of the Client’s conduct.

 

17. On Booking the services and solutions referred to in these terms and conditions and throughout this website, the client accepts that The Kitchen Gallery Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy fees and charges are at a set at rate of a minimum £250.00 per hour with working time estimated at a minimum time allocation of between 30 hours to 50 hours of work for The Kitchen Gallery Design Consultancy, a minimum of 50 hours for Gallery Kitchen Design & Interiors and a minimum of 60 hours for G2Techk Solar Heating & Energy. The time allocation estimate can rise beyond that for each of the three businesses, dependent on the specification of the project and the considerations referred to at each of the clauses above and throughout these terms and conditions.

 

18. The Client agrees to pay in advance to The Kitchen Gallery Design Consultancy, and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy a minimum of the equivalent of 20 hours work at the rate of £250.00 per hour and that the client remains liable for any additional time costs, charges, fees and service costs above the 20 hours as referred to in these terms and conditions, the general terms and conditions of this website and those in any contract agreement and or installation document can be clawed back from any deposit, fee, charges and or costs already paid by the Client.

 

19. The Client accepts that any contractual and additional fees, charges, deposits, and or costs that are paid and or that are identified on any contract and or any installation document are non refundable in such circumstances where the Client and or any person, persons, individual, legal firm, business, company, organisation and or entity connected to the Client has affected and or prevented or delayed the design, administration, safety requirements, service, consultations and or installation task of The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy and or where the Client and any person or persons, individual, legal firm, business, company, organisation and or entity connected to the Client has caused loss of business, directly or indirectly to The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.

 

20. The Client accepts liability where the Client has breached their contract with The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy. The Client accepts liability where The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy has suffered loss of business from the Client and or where the Client and or any person, persons, individuals, legal firm, business, company , organisation or entity connected to the Client has caused loss of business from another existing or potential Client of The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.

 

21. The Client and or any person, persons, individuals, legal firm, business, company, organisation or entity connected to the Client shall remain liable for damages and compensation where they have caused either loss of business to The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy and or where the Client and or any person, persons, individuals, legal firm, business, company , organisation or entity connected to the Client have caused loss of business from another potential or existing client of The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.

 

22. The Client and or any person, persons, individuals, legal firm, business, company , organisation or entity connected to the Client remain liable for damages and compensation are found by The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy to have defamed the reputation of The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy and or in circumstances where the Client and or any person, persons, individuals, legal firm, business, company , organisation or entity connected to the Client has not given The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy the opportunity to resolve any issues that may have occurred in the contractual process. At all times the Client is required to preserve the good reputation of The Kitchen Gallery Design Consultancy, Gallery Kitchen Design, Interiors & Furniture and G2Techk Solar Heating & Energy.

 

23. On booking of the services of The Kitchen Gallery Design Consultancy, and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy, at all times, the Client accepts their liability for contractual and additional fees, charges and costs at at the rate of at least £250 per hour ( This may be higher dependent on the nature, specification and complexity of the project ) and that the client is liable for payment of all contracted and any additional charges, fees and costs for all appointments, all general consultations, all administration, all design time, all design consultations, all research for the project and all meetings on site, at showroom and at or with and travelling to and from any fabricators, manufacturers and suppliers and this also includes any time travelling back and return to of and to and from the clients and for all meetings, time spent in office, on telephone calls, internet conference calls, emails, letters, and any time spent dealing with any form of administration or task that present itself as a consequence of the project.

 

24. The rate of £250 per hour shall also apply for any legal costs incurred by The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy and for all contractual and additional charges, fees and costs caused as a consequence of the Client’s requests, requirements and Client conduct during the project or after and for contractual and additional administration, legal service, assistance and advice costs and any further consultation caused by the Client or any person, persons, individuals, legal firm, business, company, organisation or entity connected to the Client.

 

25. The Client accepts their liability for all contractual and additional fees, charges and costs at all times at the rate of at least £250 per hour ( this may be higher dependent on the nature, specification and complexity of the project ) for the cancelling of appointments and or services and or where the Client, and or any person, persons, individuals, legal firm, business, company, organisation or entity connected to the Client causes the project to be put on hold ,delayed and or where the Client and or any person, persons, individuals, legal firm, business, company, organisation or entity connected to the Client causes the delay of or failure of the Client to make any contractual and additional payments owed to The Kitchen Gallery Design Consultancy, and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.

 

26. The Client shall at all times remain liable for The fees and charges of £250 per hour for any administration time spent by The Kitchen Gallery Design Consultancy, and or by Gallery Kitchen Design, Interiors & Furniture and or by G2Techk Solar Heating & Energy for dealing with any banking, legal, paralegal or advice service matters related to the project and or as a consequence of the Client’s or any person, persons, individuals, legal firm, business, company, organisation or entity connected to the Client’s conduct or actions in the matter or project whatsoever. The Client accepts liability for the payment of all contractual and additional fees, costs and charges in full and even where there is delay to the services booked by the client.

 

27. The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserves the right to withhold any products, goods, services, designs, further consultations and installation rights from the client in the event of failure by the Client to provide the design and budget information referred to in these terms and conditions and or on any contractual agreement and or where the Client has failed to perform to and abide by these terms and conditions, the general terms and conditions of this website, on any written contractual agreement and or on any installation document. Full legal title and entitlement to those products, goods, services, designs, further consultations and installation rights shall not pass to the Client until the Client has resolved these issues with and to the satisfaction of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.

 

28. The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserves the right to withhold any products, goods, services, designs, further consultations and installation rights from the client in relation to any damages and compensation owed to The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy for any direct or indirect loss of business caused by the Client and or by any person, persons, individuals, legal firm, business, company, organisation or entity connected to the Client. Full legal title and entitlement in those products, goods, services, designs, or consultations and entitlement shall not pass to the Client until the Client has resolved these issues with and to the satisfaction of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.

 

29. The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserves the right to withhold any products, goods, services, designs, further consultations and installation rights from the client where the Client is owing contractual and additional charges, fees and costs, and where legal costs and administration time spent costs are owed to The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy by the Client as referred to throughout these terms and conditions and including those described in any written contract and any additional installation document. Full title and entitlement to any products, goods, services, designs, further consultations and installation rights shall not pass to the client until the Client has resolved these issues with and to the satisfaction of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy and until the Client has settled payment in full of all monies owed to the Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.

 

30. The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserves the right to withhold any products, goods, services, designs, further consultations and installation rights from the Client where the Client and or any person, persons, individuals, legal firm, business, company, organisation or entity connected to the Client has caused the project or projects to be placed on hold, delayed, cancelled. Full title and entitlement to any products, goods, services, designs, further consultations and installation rights shall not pass to the Client until the Client has resolved these issues with and to the satisfaction of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy and until the Client has compensated The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy for any delay or cancellation. 

 

31.  The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserves the right to withhold any products, goods, services, designs, further consultations and installation rights from the client where any issues have occurred affecting The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy as a consequence of the Client’s conduct and actions and or conduct and actions of any person, persons, individuals, legal firm, business, company, organisation or entity connected to the Client. Full legal title and entitlement in those products, goods, services, designs, further consultations and installations rights shall not pass to the Client until the Client has resolved any issues with and to the satisfaction of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy and until the Client has compensated The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy

 

32. The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserves the right to withhold any products, goods, services, designs, further consultations and installation rights from the client where the Client any person, persons, individuals, legal firm, business, company, organisation or entity connected to the Client has defamed the businesses and reputation of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.Full legal title and entitlement in those products, goods, services, designs, further consultations and installations rights shall not pass to the Client until the Client has resolved any issues with and to the satisfaction of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy and until the Client has compensated The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy for that defamation.

 

33. The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserves the right to withhold any products, goods, services, designs, further consultations and installation rights from the client where the Client is in breach of these terms and conditions, in breach of the general terms and conditions of this website and any terms and conditions on any contract agreement and or installation document. Full legal title and entitlement in those products, goods, services, designs, further consultations and or installation rights of the Client shall not pass to the client until the client has resolved these issues to the satisfaction of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.

 

34. The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserves the right to withhold any products, goods, services, designs, further consultations and installation rights from the client where the Client failed to attend an appointment or appointments, or where the Client is in breach of these terms and conditions and any terms and conditions on any contract agreement and or installation document. Full legal title and entitlement in those products, goods, services, designs, further consultations and installation rights shall not pass to the Client until the Client has resolved these issues with and to the satisfaction of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy and the Client has compensated The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy for the missed appointment or appointments or for any loss associated to the Client’s breach of these terms and conditions, of this websites general terms and conditions and those of any written contract and or installation document.

 

35. The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserves the right to withhold products, goods, services, designs, further consultations and or installation rights from the Client, where the Client and or any person, persons, individuals, legal firm, business, company, organisation or entity connected to the Client has caused obstruction to or difficulties for The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy. Full legal title and entitlement of those products, goods, services, designs, further consultations and or installation rights of the Client shall not pass to the client until the Client has resolved these issues with and to the satisfaction of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.

 

36. The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserves the right to withhold any products, goods, services, designs, further consultations and installation rights from the Client where the Client or any person, persons, individuals, legal firm, business, company, organisation or entity connected to the Client has caused a loss of business or additional loss of business from another potential or existing client as a consequence of the Client’s conduct or actions or the conduct or actions of any person, persons, individuals, legal firm, business, company, organisation, or entity connected to the Client. Full legal title and entitlement in those products, goods, services, designs, further consultations and installation rights shall not pass to the Client until the client has resolved these issues with and to the satisfaction of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy and until the Client has compensated in full to its satisfaction The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.

 

37. The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserve the right to withhold any products, goods, services, designs, further consultations and installation from the client where the Client and or any person, persons, individuals, legal firm, business, company, organisation, or entity connected to the Client has prevented either The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy from completing any part or all parts of its tasks on the project and or has caused The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy to have to spend additional time seeking legal service assistance and advice.

 

38. Full legal title and entitlement in those products, goods, services, designs, further consultations and or installation rights of the Client shall not pass to the client until the client has resolved any issues with and to the satisfaction of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy and until the Client has compensated in full to its satisfaction The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy for time spent on seeking legal costs at the rates referred to earlier of £250 per hour, for the cost of legal services, assistance and advice and for the costs of legal representation in any court of law or mediation services in pursuit of acting on behalf of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy in relation to this project or any dispute caused by the Client and or caused by any person, persons, individuals, legal firm, business, company, organisation, or entity connected to the Client.

 

39. At all times, the Client accepts that The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy will not be liable for any consequential loss or refunds to the Client or legal costs of the Client whatsoever that may result from the services and solutions being delayed or not completed as referred to throughout these terms and conditions, or for the reasons referred to throughout these terms and conditions, in the general terms and conditions of this website or in any written contract agreement or any installation document and for any legal costs of the Client as a consequence of dispute or  mediation or by way of the Client’s legal costs relating to any claim for defamation and or loss of business by The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.

 

40. Any description of the products, services and solutions and their effects is as is set out in the current descriptive literature issued by The Kitchen Gallery Kitchen Design Consultancy, and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy. Under these circumstances, no additional representations shall bind The Kitchen Gallery Kitchen Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy unless the same has been put into writing and signed by a director/ proprietor/ partner of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.

 

23. The type of specification and arrangement of each item of service, solution and or material used in the service, solution, product and or any installation shall be as determined by The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy.  The policy of  The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy is to develop and improve and therefore it reserves the right to vary the presentation,  service time, presentation time and date, design, specification,  plan or installation without prior notice to the Client. The Client accepts that The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy reserves the right to vary the time and performance of the services and solutions described in these terms and conditions, its general terms and conditions and any written contract agreement or installation document for any reason whatsoever.

 

24. The Client accepts that The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy do not advise Clients to enter into any borrowing agreement for the Client’s project/s and it is at the Client’s own risk if they choose to seek such additional funding for the project/s and or service. The Client accepts that The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy do not accept liability whatsoever where any client has borrowed funding for any project. 

 

41. The Client accepts that The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy do not accept liability for any consequential loss of any description that may result from the service and or installation, (where there is one), not being delivered, delayed, or not completed on time, at all and or for whatever reason. The Client accepts that The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy does not accept liability whatsoever for supplier, fabricator and or manufacturer delays on materials, deliveries, or installations or for reasons of force majeure.

42. The Client accepts that The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy do not accept liability whatsoever for the structural condition or integrity of the Client’s home, building, premises, land or site and or for the Client’s existing gas, water and utilities including all electrical circuits supply and cabling to and from the Client’s property, home, business, building, site or land. The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy do not accept liability for the Clients on site appliances and fittings in their home, property, building, premises, site or land. 

 

43. The Client accepts that The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy do not accept any liability whatsoever where the Client or in circumstances where the existing Client or former Client, former home owner, former or current business owner, former or existing free holder, former or existing lease holder, former or existing land owner or former or existing renter of the home, business, premises, land or site have either performed and or commissioned additional works at the home, business, premises, building, land or site that have either made existing contractual or previous work to the home, business, premises, land or site by The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design and or G2Techk Solar Heating & Energy installations or by its contractors unsafe or where such works by another party or the existing Client or former Client, former home owner, former or current business owner, former or existing free holder, former or existing lease holder, former or existing land owner or former or existing renter has affected any warranties and or guarantees and or affected insurance risk and or health and Safety risk of either The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy or any other works carried out by any other contractor at the home, business, premises, building, land or site in question.

 

44. The Client accepts that The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy do not accept any liability whatsoever where The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design and or G2Techk Solar Heating & Energy were not informed of any additional works by the existing Client or former Client, former home owner, former or current business owner, former or existing free holder, former or existing lease holder, former or existing land owner or former or existing renter and all referred to here had not commissioned The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design and or G2Techk Solar Heating & Energy to carry out those commissioned works and or were unknown to The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design and or G2Techk Solar Heating & Energy at the time of those works.

 

45. The Client accepts that The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design, Interiors & Furniture and or G2Techk Solar Heating & Energy do not accept any liability whatsoever where they were not commissioned to assist with any unilateral works carried out by or commissioned by the existing Client or former Client, former home owner, former or current business owner, former or existing free holder, former or existing lease holder, former or existing land owner or former or existing renter and or where it has been revealed that those works were carried out independent of The Kitchen Gallery Design Consultancy and or Gallery Kitchen Design and or G2Techk Solar Heating & Energy. 

 

46. Security Notice: When entering the premises of The Kitchen Gallery Design Consultancy, you do so in acceptance that video & audio recordings may be in operation for the purposes of security, prevention or detection of crime, self regulatory compliance, & to establish the existence of facts where needed. This security notice is clearly displayed on the entrance door to the premises. 

 

At the clients’ first appointment at our premises and or on site, we shall refer the client to these terms and conditions, those on the T&C’s page of this website and on any written contract or agreement.

 

To book this service please submit your details and information on our contact page or care of our consultancy email: kitchengallerydesign@tiscali.co.uk

 

You may also book this service by way of any social media message, telephone call, or internet conference call.

By continuing to use the site, you agree to the use of cookies. more information

The cookie settings on this website are set to "allow cookies" to give you the best browsing experience possible. If you continue to use this website without changing your cookie settings or you click "Accept" below then you are consenting to this.

Close